By accessing and using getwebdeveloper.online, you agree to comply with and be bound by the following Terms and Conditions. If you do not agree with these terms, please do not use our website or services.
Our website provides web development consultation and related digital services including website development, technical SEO audits, manual QA testing, and bug reporting. All services are provided based on client requirements and mutual agreement.
Service timelines, deliverables, and pricing are finalized after an initial discovery call and confirmed in writing before work begins.
All website content including text, graphics, branding, logo, and design elements are the property of Sachin Raut (getwebdeveloper.online) and may not be copied, reproduced, or distributed without explicit written permission.
Upon full payment for a completed project, the client receives full ownership of all custom-built code, design files, and assets created specifically for their project. No lock-in, no recurring ownership fees.
We strive to provide accurate and reliable services; however, the website and services are provided on an "as-is" basis without warranties of any kind, express or implied.
We are not responsible for any indirect, incidental, or consequential damages arising from the use of our website or services, including but not limited to loss of data, revenue, or business opportunities.
Standard payment structure: 30% upfront before work begins, 40% after design approval, and 30% upon final delivery. Milestone-based payments are available for larger projects.
All payments are non-refundable once the respective milestone has been delivered and approved. Accepted methods: bank transfer, UPI, PayPal, and Stripe.
The content on this website — including service pages, process descriptions, feature lists, sample reports, comparison tables and frequently asked questions — is provided for general information only. It describes how work of this kind is commonly approached and does not constitute a quotation, a specification, a proposal, or an offer capable of acceptance.
Nothing published on this website forms part of any agreement between us. The scope of work, deliverables, inclusions, exclusions, timelines and fees applicable to your project are set out solely in a written proposal or agreement issued to you and confirmed before work begins. Where anything on this website differs from that written agreement, the written agreement prevails.
Any figures, statistics, sample reports, mock-ups, screenshots or example outputs shown on this website are illustrative only. They are presented to demonstrate format and approach, are not drawn from any specific client engagement unless expressly stated, and are not a representation of results you should expect.
Search engine rankings, organic traffic, page speed scores, Core Web Vitals measurements, conversion rates, enquiry volumes and sales are influenced by a very large number of factors, many of which are outside our control. These include but are not limited to: search engine algorithm changes, competitor activity, your hosting environment, third-party plugins and scripts, browser and device behaviour, your own content and pricing decisions, market conditions, and changes you or others make to the website after delivery.
Accordingly, we do not warrant, promise or guarantee any particular ranking position, traffic level, performance score, conversion rate or commercial outcome, and no statement made on this website, in correspondence, or in conversation should be interpreted as such a guarantee. Any targets, benchmarks or estimates discussed are good-faith professional judgements, not commitments.
Where a specific, measurable outcome is genuinely agreed as a deliverable, it will be recorded expressly and unambiguously in the written agreement for your project. Nothing else constitutes a performance commitment.
Timelines and cost estimates are prepared on the basis of the scope agreed at the outset and on the assumption that content, access, credentials, approvals and feedback are supplied by you within reasonable time. Delays in receiving these will extend delivery dates correspondingly, and we are not liable for any consequence of such delays.
Requests for work outside the agreed scope are treated as change requests. These will be quoted separately and will not proceed until confirmed by you in writing. Estimates are not fixed-price quotations unless expressly described as such.
Projects commonly rely on third-party products and services, including but not limited to hosting providers, domain registrars, content management systems, plugins and themes, payment gateways, courier and logistics platforms, analytics tools, email delivery services and content delivery networks.
These are supplied and operated by their respective providers under their own terms, pricing and service levels. We do not control their availability, performance, pricing, feature set or continued existence, and we accept no liability for their acts, omissions, outages, policy changes, fee changes or discontinuation. Any licence, subscription or transaction fees charged by such providers are your responsibility unless expressly agreed otherwise in writing.
Where a third-party service is required for a feature to function, that feature is dependent on the continued availability of that service.
You are responsible for the accuracy, legality and ownership of all content, images, logos, text, data and materials you supply for use in your project. You confirm that you hold the necessary rights or licences for such materials, and you agree to indemnify us against any claim arising from their use.
You are responsible for reviewing and approving work at each agreed stage. Approval of a stage confirms your acceptance of that work, and any subsequent changes to it are treated as change requests under clause 08.
Following handover, you are responsible for the ongoing operation of the website, including software updates, backups, security and hosting, unless a separate written maintenance arrangement is in place.
We may update these Terms at any time without prior notice. Continued use of the website after updates constitutes your acceptance of the revised Terms. We encourage you to review this page periodically.
These Terms are governed by the laws of India, and the courts at Mumbai, Maharashtra shall have jurisdiction over any dispute arising from them.
Reach out directly — we'll respond within 24 hours.
Email: sachinraut0310@gmail.com